Orange County NC Website
Browse       Search
3 <br />Revised 01/24 <br />circumstances, and in accordance with federal, state and local laws and regulations applicable to the performance of these Services. No <br />other representations, warranties or guarantees, express or implied, are made or intended by this Agreement or the Architect’s services. <br />The Architect shall without additional cost to the Owner, correct errors or omissions in its documents, provided such corrections are <br />within the original scope of services. <br />3.2.2 The Designer shall be responsible for all errors or omissions, in the drawings, specifications, and other documents prepared by the <br />Designer or its Consultants. It shall be the responsibility of the Designer throughout the period of performance under this Agreement to <br />use reasonable professional care and judgment to guard the Owner against defects and deficiencies in the Project. <br />3.2.3 The Designer shall correct at no additional cost to the Owner any and all errors, omissions, discrepancies, ambiguities, mistakes or <br />conflicts in the drawings, specifications and other documents prepared by the Designer or its Consultants. <br />3.2.4 The Designer shall assure that all drawings, specifications and other documents prepared by the Designer or its Consultants <br />hereunder are in accordance with applicable laws, statutes, building codes and regulations and that all necessary or appropriate <br />applications for approvals are submitted to federal, state and local governments or agencies in a timely manner so as not to delay the <br />design or construction activities of the Project except as otherwise provided in this Agreement or in Owner’s contract with the Contractor. <br />3.2.5 The Designer and its Consultants shall perform the Services in a reasonably timely manner in accordance with all mutually agreed <br />schedules for the Project or required under this Agreement. <br />3.2.6 With mutual agreement between the Owner and Design Consultant, deductions may be made from the Design Consultant's Basic <br />Services Compensation on account of errors and omissions in the drawings, specifications and other documents prepared by the Design <br />Consultant or in the Design Consultant’s performance of its obligations under this Agreement. No deductions shall be made from the <br />Design Consultant's Basic Services Compensation on account of penalty, liquidated damages, retainage, or other sums withheld from <br />payments to Contractor. <br />3.3 Designer's Consultants <br />3.3.1 The Designer's Consultants for the project, along with their key project personnel, are listed in Attachment E to this Agreement. <br />No changes in the Consultants or key personnel indicated shall be permitted except with the prior written consent of the Owner. <br />3.3.2 All of the Designer's contracts with its Consultants shall be in writing and shall expressly provide that if this Agreement is <br />terminated for any reason, the Owner may, at its sole option, request the assignment of the Consultants' contract with the Designer, that <br />such assignment shall automatically take place upon notification in writing by the Owner to the Consultants and the Consultants shall <br />continue to be bound by the contract after such assignment. A copy of each contract between the Designer and a Consultant shall be <br />furnished to the Owner within seven (7) days of its execution. <br />ARTICLE 4 <br />BASIC SERVICES <br />4.1 Basic Services <br />4.1.1 The Designer shall perform as Basic Services the Services described herein and in Attachment B to this Agreement. <br />4.1.2 The Basic Services will be performed by the Designer in the phases described in Attachment B. <br /> <br />Docusign Envelope ID: ED9774D9-AC0C-4CB2-997F-EA672B7B6C5D