Orange County NC Website
Browse       Search
DocuSign Envelope ID:78B556CA-0O28-4315-8EF4-948059C1C6F0 <br /> 38 <br /> 20.3 When payment is requested or made on an account of stored materials, such materials <br /> must be stored on the Owner's property at such places and in such a manner as may be <br /> designated by the Designer. However, in the sole discretion of the Owner, with permission <br /> in writing from the Designer and Owner and under such circumstances as may be determined <br /> by the Owner, such materials may be stored in a bonded warehouse. The location and <br /> conditions for storage of such materials away from the Owner's property in a bonded warehouse <br /> shall be within the sole discretion of the Owner. Requests for Payment on account of stored <br /> materials shall be accompanied by paid invoices, bills of sale, warehouse receipts, or other <br /> documentary evidence establishing Owner's title to such materials, evidence that the stored <br /> materials are insured against loss and damage, and such other documentation as required by <br /> the Designer. Responsibility for the quantity, quality, and condition of such stored materials, <br /> whether stored on the Owner's property or away from the Owner's property, shall remain with <br /> the Contractor regardless of ownership or title. No payment shall be made on account of <br /> materials stored in a bonded warehouse unless the Contractor has acquired written permission <br /> from the Designer for such storage of materials and has complied with all conditions set forth in <br /> such permission regarding such storage of materials in a bonded warehouse. <br /> 20.4 Any Request for Payment received by the Designer on or before the fifth (5th) of the <br /> calendar month shall be certified for payment or returned for re-submission to the Contractor on <br /> or before the fifteenth (15th) of the calendar month. The Designer's certification shall be for the <br /> amount which was requested or that which the Designer has decided was justly due, and shall <br /> state in writing to the Contractor and Owner the reasons for withholding payment of any or all of <br /> the amount requested. <br /> 20.5 The Designer may fail to certify all or part of any payment requested for any of the <br /> following reasons: <br /> a) Defective Work not corrected. <br /> b) Suits, actions, or claims of any character filed against the Contractor, or due to the operations <br /> of the Contractor, or information or notice that a suit, action, or claim will be filed or has been <br /> made. <br /> c) Information or notice that a Subcontractor or a supplier has not received payment. <br /> d) The balance unpaid of the Contract Price is insufficient to complete the Work in the judgment <br /> of the Designer or Owner. <br /> e) Damage to the Owner or another contractor. <br /> f) Inability of the Contractor to meet a Completion Date, including an anticipated failure to meet <br /> a Completion Date entitling the Owner to withhold anticipated Liquidated Damages in <br /> accordance with paragraphs 13.15 and 13.17 hereof. <br /> g) Failure to furnish Submittal as required by the Contract Documents on a timely basis in <br /> accordance with the Submittal Register. <br /> h) Such other reason as to the Designer may appear prudent, proper, or equitable. When <br /> grounds for withholding certification have been corrected, the Designer shall so certify to the <br /> Revised NETPLANNER v2 <br />