Orange County NC Website
Browse       Search
4 . In Subparagraph 4 . 4 . 8 delete the words "by mediation or by arbitration" in the first <br /> sentence . <br /> E . Paragraph 4 . 5 "MEDIATION" <br /> 1 . Delete Subparagraphs 4 . 5 . 1 , 4 . 5 . 2 and 4 . 5 . 3 in their entirety. <br /> 2 . Insert a new Subparagraph 4 . 5 . 1 as follows $ "All references to mandatory mediation <br /> in the GENERAL CONDITIONS and any other Contract Documents are hereby <br /> deleted . All disputes not resolved by the Architect' s decision shall be resolved in <br /> accordance with Subparagraph 4 . 2 . 13 . " <br /> F . Paragraph 4 . 6 "ARBITRATION" <br /> 1 . Delete Subparagraphs 4 . 6 . 1 , 4 . 6 . 2 , 4 . 6 . 3 , 4 . 6 . 4 , 4 . 6 . 5 and 4 . 6 . 6 in their entirety . <br /> 2 . Insert a new Subparagraph 4 . 6 . 1 as follows : <br /> 4 . 6 . 1 "All references to mandatory arbitration in the . GENERAL <br /> CONDITIONS and any other Contract Documents are hereby deleted . All <br /> disputes not resolved by the Architect ' s decision shall be resolved in accordance <br /> with Subparagraph 4 . 2 . 13 . " <br /> VI . MODIFICATIONS OF ARTICLE 7 - CHANGES IN THE WORK <br /> A . Paragraph 7 . 2 " CHANGE ORDERS " <br /> Insert a new Subparagraph 7 . 2 . 3 as follows . <br /> 7 . 2 . 3 The Contractor shall provide a breakdown of cost or credit for a change made in <br /> accordance with Clause 7 . 3 . 3 . 1 or 7 . 3 . 3 . 4 on the form, Exhibit A, attached to <br /> these supplementary general conditions . <br /> B . Paragraph 7 . 3 " CONSTRUCTION CHANGE DIRECTIVES " <br /> 1 . In Subparagraph 7 . 3 . 1 , in the second sentence, following " deletions or other <br /> revisions " , insert " or acceleration of the time for completing the Work, " <br /> 2 . Insert a new Clause 7 . 3 . 3 . 5 as follows : <br /> 7 . 3 . 3 . 5 The Contractor shall provide a breakdown of cost or credit for a change <br /> made in accordance with Clause 7 . 3 . 3 . 1 . <br /> VII . MODIFICATIONS OF ARTICLE 8 — TIME <br /> A . Paragraph 8 . 3 "DELAYS AND EXTENSIONS OF TIME " <br /> 1 . Delete Subparagraph 8 . 3 . 1 in its entirety and in its stead the following new <br /> Subparagraph 8 . 3 . 1 . <br /> 8 . 3 . 1 If the Contractor is delayed in the commencement, prosecution, or <br /> completion of the Work by the acts , omissions , neglect or default of the Owner , <br /> or of anyone employed by the Owner, or by any damage caused by fire or other <br /> casualty of by the combined action of workmen in no way chargeable to the <br /> Contractor, or by any extraordinary condition arising out of war or government <br /> SGC - 9 <br />