Orange County NC Website
Browse       Search
DocuSign Envelope ID: B94F2D40-3B3C-47A7-86C2-6F1 B4F92C62C <br /> SECTION 00 40 01 -CONTRACT AND ADMINSTRATION FORMS <br /> SECTION 00 40 01 -CONTRACT AND ADMINSTRATION FORMS <br /> A. The following standard forms shall be utilized in the administration of the Project: <br /> 1. Form of Agreement: AIA Document A101-2017 Standard Form of Agreement Between Owner and Contractor <br /> where the basis of payment is a Stipulated Sum(Modified);A101-2017 ExhibitA Insurance and Bonds(Modified); <br /> and AIA Document A201-2017, General Conditions of the Contract for Construction. (Modified) <br /> 2. Form of Certificate of Insurance: AIA Document G715 Supplemental Attachment for Acord Certificate of <br /> Insurance 25-S. <br /> 3. Form of Performance Bond and Labor and Material Bond: AIA Document A312-2010 Performance Bond and <br /> Labor and Material Bond. <br /> a. The General Contractor will be allowed to modify the AIA A312-2010 Payment Bond as follows: <br /> 1) Amend second line of Paragraph 6.1 to delete"45 days"and substitute with"60 days". <br /> 2) Amend Paragraph 6 to add subparagraph 6.3: <br /> a) 6.3 The Surety's failure to discharge its obligations under this Section 6 shall not to be deemed to <br /> constitute a waiver of defenses the Surety or Contractor may have or acquire as to a claim. <br /> However, if the Surety fails to discharge its obligations under this Section 6, the Surety shall <br /> indemnify the Claimant for the reasonable attorney's fees the Claimant incurs to recover any sums <br /> found to be due and owing to the Claimant. <br /> 4. Form of Application for Payment: AIA Document G702-2017, Application and Certificate for Payment, and AIA <br /> Document G703-2017, Continuation Sheet. <br /> 5. Form of Contractor's Affidavit: AIA Document G706-1994 Contractor's Affidavit of Payment of Debts and Claims. <br /> 6. Form of Affidavit of Release of Liens: AIA Document G706A-1994 Contractor's Affidavit of Payment of Release <br /> of Liens. <br /> 7. Form of Consent of Surety: AIA Document G707-1994 Consent of Surety to Final Payment and AIA Document <br /> G707A, Consent of Surety to Reduction in or Partial Release of Retainage, <br /> 8. Form of Architect's Memorandum for Minor Changes in the Work: AIA Document G710-2017 Architect's <br /> Supplemental Instructions. <br /> 9. Form of Request for Proposal:AIA Document G709-2001 Proposal Request. <br /> 10. Change Order form: AIA Document G701-2017 Change Order. <br /> 11. Form of Certificate of Substantial Completion:AIA Document G704-2017, Certificate of Substantial Completion. <br /> 12. Form for Requests for Interpretation (RFIs): Document 00 63 13 Request for Interpretation.A copy of this form <br /> in Microsoft Word is available from the Architect. <br /> 13. Form of Statement of Sales Tax Paid: Document 00 62 76 Contractor's Statement of Sales Tax Paid, a copy of <br /> which is included in this project manual.A copy of this form in Microsoft Word is available from the Architect. <br /> B. The following standard forms may be utilized in the administration of the Project: <br /> 1. Form of Construction Change Directive:AIA Document G714-2017, Construction Change Directive. <br /> C. Copies of AIA standard forms may be obtained from: <br /> 1. American Institute of Architects: (800)365-2724. <br /> 2. AIA/North Carolina: (919)833-6656 voice; (919)833-2015 fax; aianc@interpath.com. <br /> 3. Group G Systems, Charlotte, NC: (704)519-0015 voice; (704)529-7329 fax;fneal@groupgsystems.com. <br /> D. The following Owner provided forms may, at the discretion of the Owner, be used in connection with this project: <br /> 1. Project directory form <br /> 2. Proposed Change form <br /> 3. Quality Control Action item form <br /> 4. RFI Log <br /> 5. Submittal Log <br /> 6. Surety Statement <br /> 7. Closeout Checklist <br /> 8. Closeout Document Release Form <br /> 9. Daily Report Form <br /> 10. Inspection Form <br /> 11. Meeting Agenda <br /> 12. New Issues Log <br /> 13. Pay Application Checklist <br /> END OF DOCUMENT 00 40 01 <br /> ©BOOMERANG DESIGN 00 40 01 -Pagel of 1 510 Meadowlands Drive,Hillsborough,NC <br /> BD#1835 ORANGE COUNTY, NC 12/07/2018 <br />