|
except by written consent containing a specific .2 Ten percent of the total compensation for Basic and
<br /> this Agreement signed by the Owner, Architect,and reference
<br /> Y Additional Services earned to•date If termination
<br /> person or entity sought to be joined. Consent to arbitration occurs during the Design Development Phase; or
<br /> involving an additional person or entity shall not constitute i
<br /> consent to arbitration of any claim, dispute or other matter in .3 Five percent of the total compensation for Basic and J
<br /> question not described in the written consent or with a person Additional Services earned to date If termination
<br /> or entity not named or described therein.The foregoing agree- occurs during any subsequent phase.
<br /> ,ment to arbitrate and other agreements to arbitrate with an
<br /> additional person or entity duly consented to by the parties to
<br /> this Agreement shall be specifically enforceable in accordance ARTICLE 9
<br /> with applicable law in any court having jurisdiction thereof.
<br /> MISCELLANEOUS PROVISIONS
<br /> 7.4 The award rendered by the arbitrator or arbitrators shall he
<br /> final,and judgment may he entered upon it in accordance with 9.1 Unless otherwise provided, this Agreement shall be gov-
<br /> applicable law in any court having jurisdiction thereof. erned by the law of the principal place of business of the
<br /> Architect.
<br /> 9.2 Terms in this Agreement shall have the same meaning as
<br /> ARTICLE 8 those in AIA Document A201, General Conditions of the Con-
<br /> tract for Construction,current as of the date of this Agreement.
<br /> TERMINATION, SUSPENSION OR ABANDONMENT
<br /> 9.3 Causes of action between the parties to this Agreement
<br /> 8.1 This Agreement may be terminated by either party upon pertaining to acts or failures to act shall be deemed to have
<br /> not less than seven days' written notice should the other party accrued and the applicable statutes of limitations shall co
<br /> fail substantially to perform in accordance with the terms of this mence to run not later than
<br /> Agreement the date of Substantial Com-
<br /> Agreement through no fault of the party initiating the termination. plction for acts or failures to act occurring prior to Substantial
<br /> Completion,
<br /> 8.2 If the Project is suspended by the Owner for more than 30 Payment for acts or failures ailur'es to act occurring final after Substantial
<br /> consecutive days, the Architect shall be compensated for scr- Completion.
<br /> vices performed prior,to notice of such suspension, When the
<br /> Project is resumed, the Architect's compensation shall he equi- 9.4 The Owner and Architect waive all rights against each
<br /> tably adjusted to provide for expenses incurred in the interrup_ other and against 'the contractors, consultants, agents and
<br /> lion and resumption of the Architect's services. employees of the other for damages,but only to the extent cov-
<br /> ered by property insurance during construction, except such
<br /> 8.3 This Agreement may he terminated by the Owner upon rights as they may have to the proceeds of such insurance as set
<br /> not less than seven days' written notice to the Architect in the forth in the edition of AIA Document A201,General Conditions
<br /> event that the Project is permanently ahandnnc•d. If the Project of the Contract for Construction, current as of the date of this • `r
<br /> is abandoned by the Owner for more than 90 consecutive days, Agreement.The Owner and Architect each shall require similar
<br /> the Architect may terminate this Agreement by giving written waivers from their contractors, consultants and agents.
<br /> notice.
<br /> 9. The Owner and Architect,8.4 Failure of the Owner to make payments to the Architect in hesuccessors,ir partners, assignrespectively,
<br /> and dtlegal representatives to
<br /> a
<br /> •
<br /> ccordance with this Agreement shall he considered substantial the other party to this Agreemerit and to the partners, succes-' - '
<br /> nonperformance and cause for termination. sors,assigns and legal representatives of such other party with
<br /> 8.5 If the Owner fails to make payment when due the Archi- respect to all covenants of this Agreement. Neither Owner nor • '
<br /> tect for services and expenses, the Architect may, upon seven Architect shall assign this Agreement without the written con-
<br /> days'written notice to the Owner,suspend performance of ser-
<br /> vices under this Agreement. Unless payment in fill is received 9.6 This Agreement represents the entire and integrated agree- .
<br /> by the Architect within seven clays of the date of the notice,the ment between the Owner and Architect and supersedes all
<br /> suspension shall take effect without further notice.in the event prior negotiations, representations or agreements, either writ-
<br /> of a suspension of services, the Architect shall have no liability ten or oral. This Agreement may be amended only by written
<br /> to the Owner for delay or damage caused the Owner because instrument signed by both Owner and Architect.
<br /> of such suspension of services.
<br /> 9.7 Nothing contained in this Agreement shall create a contrac-
<br /> 8.6 In the event of termination not the fault of the Architect, tual relationship with or a cause of action in favor of a third
<br /> the Architect shall he compensated for services performed prior party against either the Owner or Architect. `
<br /> to termination,together with Reimbursable Expenses then due
<br /> 9.8 1Inlcss otherwise provided in this Agreement,the Architect
<br /> and all Termination Expenses as defined in Paragraph 8.7.
<br /> and Architect's consultants shall have no responsibility for the
<br /> 8.7 Termination Expenses arc in addition to compensation for discovery,presence,handling, removal or disposal of or expo-
<br /> Basic and Additional Services, and include expenses which are sure of persons to hazardous materials in any form at the Project
<br /> directly attributable to termination,Termination Expenses shall site, including but not limited to asbestos, asbestos products,
<br /> he computed as a percentage of the total compensation for polychlorinated biphenyl(PCB)or other toxic substances.
<br /> Basic Services and Additional Services earned to the time of tcr-
<br /> minatian, as follows: 9.9 The Architect shall have the right to include representa- .
<br /> - tions of the design of the Project,including photographs of the
<br /> .1 Twenty percent of the total compensation for Basic exterior and-interior, among the Architect's promotional and
<br /> •
<br /> and Additional Services earned to date if termination professional materials. The Architect's materials shall not J •
<br /> occurs before or during the predesign,site analysis,or include the Owner's confidential or proprietary information if
<br /> Schematic Design Phases: or the Owner has previously advised the Architect in writing of
<br /> 7 B14I-1987 AIA DOCUMENT 8141 • OWNER•ARC:IIITECT'AGREEMENT• FOURTEENTH EDITION• AIA • ©19A7
<br /> THE AMERI(:AN INSTITUTE OF ARCHITECTS,1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C.20006
<br />
|