Agenda - 12-11-2007-4lxtr - Laserfiche WebLink

Browse Search

equipment, materials, supplies and fumishings with the Work of the Contractors is required and is not an Additional Service; 3.12.3 Services related to determination of space needs, programming, internal traffic studies or ocher utilization of the Project are Addiilonai Services; 3.12.4 Warranty inspections during the warcanty period of the Project an; required and are not Additional Services; 3.12.5 Services made necessary by the failure to perform by or bankruptcy of a Contractor is a required Service and is not an Additional Service; 3.12.6 Preparation for and serving as a witness in connection with any public or private hearing or arbitration mediation or legal proceeding relating to the Project is a required Service and is not an Additional Service; 3.12.7 Assisting the Owner in public relations activities and preparing informakion for and attending public meetings is a required Service, not an Additional Service; and 3.12.8 Services related to move-in including preparing and soliciting responses to requests for proposals, preparing and coordinating the execution of contracts, conducting pre-moving conferences, administering khe contract for moving activities in conjunction vrith the move-in for the Project and providing on- site personnel to oversee the relocation of furniture and equipment by the movers white actual move-in is in progress are Additional Services; provided, however, that coordination of the Work of the Contractors with move-in by the Owner in accordance with the Master Schedule is required and is not an Additional Service. ARTICLE 4 TIME FOR PERFORMANCE 4.1 Duration The commencement date for the CMAR's Services shall be the date of execution of this Agreement by the Owner as staled herein or the date on which the Owner issues to the CMAR a written instruction to proceed with Services, whichever is earlier. The duration of the CMAR's Services under this Agreement shah be from the date of this Agreement through the issuance of the certificate of final completion, plus the one- year CMAR warranty phase services. 4.2 Master Schedule The CMAR's Services shall be performed for the periods of time indicated in the approved Master Schedule. Firm dates for substantial complefwn and final completion of the Project shall also be taxed. At that time the CMAR represents that the Masser Schedule has been reviewed in detail, that the Contractors participated in its preparation, that ail of the activities which impact, limit, or otherwise affect the time of completion of the Work are shown in the Master Schedule and that ail of the activities of others which impact, limit, or otherwise affect the start, duration, or completion of the CMAR's activities are also shown. The CMAR further represents that the CMAR can and will campiete each activity vrithin the time shown for that activity. Time is of the essence with respect to each such activity and completion date. 4.3 Non-waiver If the CMAR submits a construction schedule, progress report, or any other document that indicates or otherwise expresses an intention to achieve cornpietion of the Work prior to any established completion date, no liability of the Owner to the CMAR for any failure of the CMAR io so complete the Work shall be created or implied. 4.4 Schedule Adjustment If the CMAR and its Contractors, for reasons beyond their control, are delayed In beginning any activity, the CMAR shalt, nevertheless, have the same number of days as is shown in the Master Schedule For the activity, and the affected activity and any succeeding activity that is dependent upon that activity shall be adjusted accardingiy; provided that at any time the Owner, by means of a Change Order, may require the CMAR to work overtime, to increase labor forces or to take any necessary or appropriate action to decrease the time required for any activity, and the CMAR shall be entitled to an adjustment in the Contract Price computed in accordance with Article 5 of these General Conditions. 4.5 Ear1y Start jiVot used.] 4.6 eco e 16