Orange County NC Website
arisen.In no event shall the demand for arbitration be made after the date when institution of legal or equitable proceedings based <br /> on such claim,dispute or other matter in question would be barred by the applicable statute of limitations. <br /> 1.3.5.4 No arbitration arising out of or relating to this Agreement shall include, by consolidation or joinder or in any other <br /> manner, an additional person or entity not a party to this Agreement, except by written consent containing a specific reference to <br /> this Agreement and signed by the Owner, Architect, and any other person or entity sought to be joined. Consent to arbitration <br /> involving an additional person or entity shall not constitute consent to arbitration of any claim,dispute or other matter in question <br /> not described in the written consent or with a person or entity not named or described therein. The foregoing agreement to <br /> arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to this Agreement shall <br /> be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof. <br /> 1.3.5.5 The award rendered by the arbitrator or arbitrators shall be final, and judgment may be entered upon it in accordance <br /> with applicable law in any court having jurisdiction thereof. <br /> 1.3.6 CLAIMS FOR CONSEQUENTIAL DAMAGES <br /> The Architect and the Owner waive consequential damages for claims, disputes or other matters in question arising out of or <br /> relating to this Agreement.This mutual waiver is applicable,without limitation,to all consequential damages due to either party's <br /> termination in accordance with Paragraph 1.3.8. <br /> 1.3.7 MISCELLANEOUS PROVISIONS <br /> 1.3.7.1 This Agreement shall be governed by the law of the principal place of business of the Architect, unless otherwise <br /> provided in Paragraph 1.4.2. <br /> 1.3.7.2 Terms in this Agreement shall have the same meaning as those in the edition of AIA Document A201, General <br /> Conditions of the Contract for Construction,current as of the date of this Agreement. <br /> 1.3.7.3 Causes of action between the parties to this Agreement pertaining to acts or failures to act shall be deemed to have <br /> accrued and the applicable statutes of limitations shall commence to run not later than either the date of Substantial Completion <br /> for acts or failures to act occurring prior to Substantial Completion or the date of issuance of the final Certificate for Payment for <br /> acts or failures to act occurring after Substantial Completion. In no event shall such statutes of limitations commence to run any <br /> later than the date when the Architect's services are substantially completed. <br /> 1.3.7.4 To the extent damages are covered by property insurance during construction, the Owner and the Architect waive all <br /> rights against each other and against the contractors, consultants, agents and employees of the other for damages, except such <br /> rights as they may have to the proceeds of such insurance as set forth in the edition of AIA Document A201,General Conditions <br /> of the Contract for Construction, current as of the date of this Agreement. The Owner or the Architect, as appropriate, shall <br /> require of the contractors, consultants, agents and employees of any of them similar waivers in favor of the other parties <br /> enumerated herein. <br /> 1.3.7.5 Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in favor of a third <br /> party against either the Owner or Architect. <br /> 1.3.7.6 Unless otherwise provided in this Agreement, the Architect and Architect's consultants shall have no responsibility for <br /> the discovery,presence,handling,removal or disposal of or exposure of persons to hazardous materials or toxic substances in any <br /> form at the Project site. <br /> 1.3.7.7 The Architect shall have the right to include photographic or artistic representations of the design of the Project among <br /> the Architect's promotional and professional materials.The Architect shall be given reasonable access to the completed Project to <br /> make such representations. However, the Architect's materials shall not include the Owner's confidential or proprietary <br /> information if the Owner has previously advised the Architect in writing of the specific information considered by the Owner to <br /> be confidential or proprietary. The Owner shall provide professional credit for the Architect in the Owner's promotional materials <br /> for the Project. <br /> 1.3.7.8 If the Owner requests the Architect to execute certificates, the proposed language of such certificates shall be submitted <br /> AIA DOCUMENT B141-STANDARD FORM AGREEMENT- 1997 EDITION-AIA-COPYRIGHT 1997-THE AMERICAN INSTITUTE OF ARCHITECTS, <br /> 1735 NEW YORK AVENUE N.W.,WASHINGTON,D.C. 20006-5292.WARNING:Unlicensed photocopying violates U.S.copyright laws and will subject the <br /> violator legal prosecution.This document was electronically produced with permission of the AIA and can be reproduced without violation until the date of expiration <br /> as noted below. <br /> Electronic Format B141-1997 <br /> User Document:40101 --9/18/2001.AIA License Number 119648,which expires on 9/30/2001 --Page#7 <br />